ILNews

Justices address economic loss rule in 2 opinions

Back to TopE-mailPrintBookmark and Share

In two separate rulings involving the “economic loss rule,” the Indiana Supreme Court ruled against a library seeking to hold subcontractors and an engineer responsible for negligence, and in favor of a bank in its tort claim against a title company.

In Indianapolis-Marion County Public Library v. Charlier Clark & Linard, P.C., et al., No. 06S05-0907-CV-332, the justices dealt the library a blow in its attempt to recover damages for repair costs and other fees because of a delay in the construction of the Central Library in Indianapolis. Construction was delayed after problems were discovered in the concrete used for the parking garage and foundation of the library. The library brought a lawsuit against the architect, general contractor, and various subcontractors for negligence. The library settled with the architect and general contractor, with whom it had a contractual relationship.

The trial court granted the remaining defendants’ motion for summary judgment, finding the negligence claims were barred by the economic loss rule. The Indiana Court of Appeals majority affirmed.

In the IMCPL case, the justices extensively examined the economic loss rule and held that it applies in the instant case. The library is connected with the defendants through a network or chain of contracts in which the parties allocated their respective risks, duties, and remedies, and those contracts - not negligence law - govern the outcome of the library’s claims, wrote Justice Frank Sullivan.

“From the outset of the project, the Library looked to a series of contracts to establish the relative expectations of the parties. And reliance on contract law in this regard is perhaps greater in construction projects than any other industry,  …” wrote the justice.

The Supreme Court also emphasized that the economic loss rule operates as a general rule to preclude recovery in tort for economic loss and does so only for purely economic loss. There are exceptions to the general rule, but those don’t apply in the library’s case.
 
But one of those exceptions does apply in the case of U.S. Bank, N.A. v. Integrity Land Title Corp., No. 17S03-1002-CV-120, which is a case of first impression. The issue is whether or not a title company, after issuing an incorrect title commitment on which the lender relied to its detriment, owes a duty in tort to the recipient to which it certified clear title to the subject real property.

The facts of this case fit within the tort of negligent misrepresentation, so applicable tort law allows U.S. Bank’s tort claim to go forward, the justices ruled.

A buyer of real property got a mortgage from lender Texcorp Mortgage Bankers, who prior to lending the money, contracted with Integrity Land Title Corp. to prepare a title commitment, close the mortgage, and provide the company with an insured first and superior mortgage lien against the subject real property. Integrity’s search uncovered no judgments against the seller of the real property, but the search failed to show a 1998 foreclosure judgment from LPP mortgage.

U.S. Bank, as successor of Texcorp’s interests, intervened in LPP’s action to foreclose the 1998 judgment lien. The bank asserted claims against Integrity of breach of contract and tort of negligent real estate closing. The trial court found Integrity wasn’t in breach of contract and not negligent because it owed no duty to U.S. Bank in tort. The two parties did not have a contract.

Justice Sullivan noted that the existence or non-existence of a contract is not the dispositive factor for determining whether a tort action is allowable where special circumstances and overriding public polices have created exceptions.

Integrity should have known that Texcorp would act in justifiable reliance on the statement in the preliminary commitment that the title was free and clear. The relationship between Integrity and Texcorp was of an advisory nature and Integrity deliberately provided specific information in response to a request by Texcorp to guide Texcorp into its transaction with a third party. Integrity also affirmatively vouched for the accuracy of the information.

 Based on this, applicable tort law allows U.S. Bank’s tort claim to go forward.
 

ADVERTISEMENT

Sponsored by
ADVERTISEMENT
Subscribe to Indiana Lawyer
  1. From his recent appearance on WRTV to this story here, Frank is everywhere. Couldn't happen to a nicer guy, although he should stop using Eric Schnauffer for his 7th Circuit briefs. They're not THAT hard.

  2. They learn our language prior to coming here. My grandparents who came over on the boat, had to learn English and become familiarize with Americas customs and culture. They are in our land now, speak ENGLISH!!

  3. @ Rebecca D Fell, I am very sorry for your loss. I think it gives the family solace and a bit of closure to go to a road side memorial. Those that oppose them probably did not experience the loss of a child or a loved one.

  4. If it were your child that died maybe you'd be more understanding. Most of us don't have graves to visit. My son was killed on a state road and I will be putting up a memorial where he died. It gives us a sense of peace to be at the location he took his last breath. Some people should be more understanding of that.

  5. Can we please take notice of the connection between the declining state of families across the United States and the RISE OF CPS INVOLVEMENT??? They call themselves "advocates" for "children's rights", however, statistics show those children whom are taken from, even NEGLIGENT homes are LESS likely to become successful, independent adults!!! Not to mention the undeniable lack of respect and lack of responsibility of the children being raised today vs the way we were raised 20 years ago, when families still existed. I was born in 1981 and I didn't even ever hear the term "CPS", in fact, I didn't even know they existed until about ten years ago... Now our children have disagreements between friends and they actually THREATEN EACH OTHER WITH, "I'll call CPS" or "I'll have [my parent] (usually singular) call CPS"!!!! And the truth is, no parent is perfect and we all have flaws and make mistakes, but it is RIGHTFULLY OURS - BY THE CONSTITUTION OF THIS GREAT NATION - to be imperfect. Let's take a good look at what kind of parenting those that are stealing our children are doing, what kind of adults are they producing? WHAT ACTUALLY HAPPENS TO THE CHILDREN THAT HAVE BEEN RIPPED FROM THEIR FAMILY AND THAT CHILD'S SUCCESS - or otherwise - AS AN ADULT.....

ADVERTISEMENT