ILNews

Justices address economic loss rule in 2 opinions

Back to TopE-mailPrintBookmark and Share

In two separate rulings involving the “economic loss rule,” the Indiana Supreme Court ruled against a library seeking to hold subcontractors and an engineer responsible for negligence, and in favor of a bank in its tort claim against a title company.

In Indianapolis-Marion County Public Library v. Charlier Clark & Linard, P.C., et al., No. 06S05-0907-CV-332, the justices dealt the library a blow in its attempt to recover damages for repair costs and other fees because of a delay in the construction of the Central Library in Indianapolis. Construction was delayed after problems were discovered in the concrete used for the parking garage and foundation of the library. The library brought a lawsuit against the architect, general contractor, and various subcontractors for negligence. The library settled with the architect and general contractor, with whom it had a contractual relationship.

The trial court granted the remaining defendants’ motion for summary judgment, finding the negligence claims were barred by the economic loss rule. The Indiana Court of Appeals majority affirmed.

In the IMCPL case, the justices extensively examined the economic loss rule and held that it applies in the instant case. The library is connected with the defendants through a network or chain of contracts in which the parties allocated their respective risks, duties, and remedies, and those contracts - not negligence law - govern the outcome of the library’s claims, wrote Justice Frank Sullivan.

“From the outset of the project, the Library looked to a series of contracts to establish the relative expectations of the parties. And reliance on contract law in this regard is perhaps greater in construction projects than any other industry,  …” wrote the justice.

The Supreme Court also emphasized that the economic loss rule operates as a general rule to preclude recovery in tort for economic loss and does so only for purely economic loss. There are exceptions to the general rule, but those don’t apply in the library’s case.
 
But one of those exceptions does apply in the case of U.S. Bank, N.A. v. Integrity Land Title Corp., No. 17S03-1002-CV-120, which is a case of first impression. The issue is whether or not a title company, after issuing an incorrect title commitment on which the lender relied to its detriment, owes a duty in tort to the recipient to which it certified clear title to the subject real property.

The facts of this case fit within the tort of negligent misrepresentation, so applicable tort law allows U.S. Bank’s tort claim to go forward, the justices ruled.

A buyer of real property got a mortgage from lender Texcorp Mortgage Bankers, who prior to lending the money, contracted with Integrity Land Title Corp. to prepare a title commitment, close the mortgage, and provide the company with an insured first and superior mortgage lien against the subject real property. Integrity’s search uncovered no judgments against the seller of the real property, but the search failed to show a 1998 foreclosure judgment from LPP mortgage.

U.S. Bank, as successor of Texcorp’s interests, intervened in LPP’s action to foreclose the 1998 judgment lien. The bank asserted claims against Integrity of breach of contract and tort of negligent real estate closing. The trial court found Integrity wasn’t in breach of contract and not negligent because it owed no duty to U.S. Bank in tort. The two parties did not have a contract.

Justice Sullivan noted that the existence or non-existence of a contract is not the dispositive factor for determining whether a tort action is allowable where special circumstances and overriding public polices have created exceptions.

Integrity should have known that Texcorp would act in justifiable reliance on the statement in the preliminary commitment that the title was free and clear. The relationship between Integrity and Texcorp was of an advisory nature and Integrity deliberately provided specific information in response to a request by Texcorp to guide Texcorp into its transaction with a third party. Integrity also affirmatively vouched for the accuracy of the information.

 Based on this, applicable tort law allows U.S. Bank’s tort claim to go forward.
 

ADVERTISEMENT

Sponsored by

facebook - twitter on Facebook & Twitter

Indiana State Bar Association

Indianapolis Bar Association

Evansville Bar Association

Allen County Bar Association

Indiana Lawyer on Facebook

facebook
ADVERTISEMENT
Subscribe to Indiana Lawyer
  1. The sad thing is that no fish were thrown overboard The "greenhorn" who had never fished before those 5 days was interrogated for over 4 hours by 5 officers until his statement was illicited, "I don't want to go to prison....." The truth is that these fish were measured frozen off shore and thawed on shore. The FWC (state) officer did not know fish shrink, so the only reason that these fish could be bigger was a swap. There is no difference between a 19 1/2 fish or 19 3/4 fish, short fish is short fish, the ticket was written. In addition the FWC officer testified at trial, he does not measure fish in accordance with federal law. There was a document prepared by the FWC expert that said yes, fish shrink and if these had been measured correctly they averaged over 20 inches (offshore frozen). This was a smoke and mirror prosecution.

  2. I love this, Dave! Many congrats to you! We've come a long way from studying for the bar together! :)

  3. This outbreak illustrates the absurdity of the extreme positions taken by today's liberalism, specifically individualism and the modern cult of endless personal "freedom." Ebola reminds us that at some point the person's own "freedom" to do this and that comes into contact with the needs of the common good and "freedom" must be curtailed. This is not rocket science, except, today there is nonstop propaganda elevating individual preferences over the common good, so some pundits have a hard time fathoming the obvious necessity of quarantine in some situations....or even NATIONAL BORDERS...propagandists have also amazingly used this as another chance to accuse Western nations of "racism" which is preposterous and offensive. So one the one hand the idolatry of individualism has to stop and on the other hand facts people don't like that intersect with race-- remain facts nonetheless. People who respond to facts over propaganda do better in the long run. We call it Truth. Sometimes it seems hard to find.

  4. It would be hard not to feel the Kramers' anguish. But Catholic Charities, by definition, performed due diligence and held to the statutory standard of care. No good can come from punishing them for doing their duty. Should Indiana wish to change its laws regarding adoption agreements and or putative fathers, the place for that is the legislature and can only apply to future cases. We do not apply new laws to past actions, as the Kramers seem intent on doing, to no helpful end.

  5. I am saddened to hear about the loss of Zeff Weiss. He was an outstanding member of the Indianapolis legal community. My thoughts are with his family.

ADVERTISEMENT